Scribd
Upload
387 views

Appendix To Tender

This document provides key contractual details for a construction project, including: - The employer is Huchems Fine Chemical Corporation and the engineer is Jurutera Perunding Wahba Sdn Bhd. - The project has two stages, with stage 1 completion in 18 months and stage 2 in 36 months. - The defects notification period is six months. - The performance security is 5% of the accepted contract amount and retention is 10% capped at 5%. - Insurance requirements and minimum amounts are defined. - The dispute adjudication board will be a sole member appointed within 56 days if the parties cannot agree.

Uploaded by

aishah
Copyright
© © All Rights Reserved
We take content rights seriously. If you suspect this is your content, claim it here.
Available Formats
Download as DOCX, PDF, TXT or read online on Scribd
387 views

Appendix To Tender

This document provides key contractual details for a construction project, including: - The employer is Huchems Fine Chemical Corporation and the engineer is Jurutera Perunding Wahba Sdn Bhd. - The project has two stages, with stage 1 completion in 18 months and stage 2 in 36 months. - The defects notification period is six months. - The performance security is 5% of the accepted contract amount and retention is 10% capped at 5%. - Insurance requirements and minimum amounts are defined. - The dispute adjudication board will be a sole member appointed within 56 days if the parties cannot agree.

Uploaded by

aishah
Copyright
© © All Rights Reserved
We take content rights seriously. If you suspect this is your content, claim it here.
Available Formats
Download as DOCX, PDF, TXT or read online on Scribd
You are on page 1/ 2

APPENDIX TO TENDER

1. With the exception of the items for which the Employers requirements have been

inserted, the following information must be completed before the Tender is


submitted.
2. All reference Clauses and Sub-Clauses provided in the Appendix To Tender shall be
constructed as reference Clauses and Sub-Clauses in Conditions of Contract for
Construction.

Item
Employers name address

Data
Huchems Fine Chemical
Corporation

Contractors name address


Engineers name address

Time for Completion of the


Works
Defects Notification Periods

Jurutera Perunding Wahba Sdn


Bhd S/L No.4, Lot 12155,
Ground Floor, Song Plaza, Jalan
Tun Jugah/Jalan Song, 93350
Kuching
Stage 1 _ 18 months
Stage 2 36 months
Six (6) months

Electronic transmission systems

Telefax and E-mails. E-mails to


be confirmed in writing

Governing Law

Law of Malaysia

Ruling language

English

Language for communications

English

Time for access to the Site

Seven (7)days after


Commencement Date
5% of the Accepted Contract
Amount

Amount of Performance
Security
Normal working hours

Monday Saturday: 8 a.m. to 5


p.m (Excluding Public Holiday)

Delay damages for the works

At the rate of 0.022% of the


Accepted Contract Amount per
day
10% of the accepted Contract
Amount

Maximum amount of delay


damages

Item

Data

Adjustment for change in cost;


Table(s) of adjustment data

Not applicable. Rises or falls in


the cost of labour, materials,
fuels and plant are not
adjustable
Not applicable
Not applicable

Total advance payment


Number and timing of
instalments
Currencies and proportions

Not applicable

Start repayment of advance


payment
Repayment amortisation of
advance payment

Not applicable

Percentage of retention

10%

Limit of Retention Money

5% of the Accepted Contract


Amount
Not Allowed

Plant and Materials for


Payment when shipped when
route to the Site
Plant and Materials for
payment when delivered to the
Site
Minimum amount of Interim
Payment Certificates
Currency/currencies of
payment
Periods for submissions of
insurance:
(a) Evidence of insurance
(b) Relevant policies
Maximum amount of
deductibles for insurance of
the Employers risks
Minimum amount of third
party
insurance
Date by which the DAB shall be
Appointed

Not applicable

As per items in the bills of


Quantities and schedules
5% of the accepted contract
amount
Ringgit Malaysia

On Commencement Date
Fourteen (14) days after
Commencement date
NIL

RM1 million per accident and


the number of accidents or
claims unlimited
56 days after Commencement
Date

The DAB shall be

One sole Member/adjudicator

Appointment (if not agreed) to


be made by

he President of Institute of
Engineers Malaysia

You might also like