1057 Shore Rd.

,
Naperville, IL 60563
Tel: 630-ENG-BITZ

QAP-04/2020

October 4, 2022

Andrew Rosenthal
430 Beverly Dr
Wilmette, IL 60091.

Subject: Solar Option for 430 Beverly Dr, Wilmette, IL 60091

Dear Mr. Rosenthal :

I am pleased to make this offer to you to install a solar photovoltaic system

on the property located at 430 Beverly Dr, Wilmette, IL 60091.

The proposed solar system will be sized at 9.45-kWp and will be a roof
mounted system to be installed on the roof of the building.

This system will be installed using the latest technology that will be
determined at the time of installation but as presented in this proposal, will
include 21 (450-W) monocrystalline panels, 21 microinverters, and
appropriate roof mounting systems.

Accordingly, it is expected that the solar plant will produce approximately

11,464 kWh of energy at a 0.05% degradation annually. This energy will be
supplied directly to your home and will be used to offset the electricity
demand that you use annually. The interconnection with the Utility, ComEd,
will be done through the standard interconnection/NetMetering agreement
with the utility. At the approximate utility rate of $0.131/kWh the solar plant
will produce an energy savings to the tune of $1,502 annually, as depicted
in the attached Cashflow analysis.

In addition to the energy savings, described above, there are several

incentives, federal and statewide, that are made available for installed solar
systems. These include the federal investment tax credit of $8,277 and the
sale of solar renewable energy credits (SREC) in the sum of $14,018.
Accordingly, the total incentive for the solar plant is estimated to be in the
range of $22,295.

It should be noted that all these incentives are guaranteed and are
supported by state and federal legislations. They are all proven and tried

[email protected]
www. wcpsolar.com
 Page 2 of 2
incentives, developed by the Government to encourage the installation of
green technology across the State of Illinois.

At the current rate of raw material and labor, it is estimated that the plant
will be installed at a total cost of $27,589. This is a lump sum cost and is valid
for 30 days from the date of this offer. This price includes material, utility
interconnection costs, labor, and all system commissioning costs.

The attached Term and Conditions is used to outline our installation

program. If you find this proposal useful and would like to lock the pricing,
please sign and return this agreement by November 3, 2022.

It is our pleasure to make this offer to you as you seek to move your
organization towards a green future and take advantage of the available
incentives within the state of Illinois.

Please contact WCP Solar at 630-ENG-BITZ (364-2489) for any clarifications

that you may need in respect of this offer or email me at
[email protected].

Kind regards

Dr. Everton Walters

President/CEO
 Brighter, Richer, Cleaner
SOL AR PH O TOV OL TAI C SYST E M
PROP OS AL

FOR

Andrew Rosenthal
9.45- KWP SOLA R PHO T OVO LT AI C
SYS TE M

Confidential Page i 10/4/2022

Copyright © 2007 WCP Solar Services QA-CCA-002
 Proposal for Engineering of Solar Photovoltaic System

SOLAR PHOTOVOLTAIC PROJECT

SUBMITTED
OCTOBER 4, 2022

This document contains proprietary

information and is submitted for the WCP SOLAR SERVICES, LLC
expressed purposes of securing a bid 1057 SHORE RD.
to provide Engineering Procurement NAPERVILLE, IL 60563
and Construction (EPC) Services for USA
the installation of a Photovoltaic
Systems. (630) ENG-BITZ (Office)

Copyright © 2007 WCP Solar Services, LLC

2009 Use with permission
 Table of Contents

Table of Contents ............................................................................................................... iii

Solar Photovoltaic System Proposal ................................................................................... 1

SECTION I. Executive Summary .................................................................................. 1

§1.01 The Project ........................................................................................................ 1
§1.02 Profile of Proposing Firm ................................................................................. 1

SECTION II. The Proposal .............................................................................................. 3

§2.01 Solar Photovoltaic (PV) System ....................................................................... 3
§2.02 System Production ............................................................................................ 3

SECTION III. Proposed Scopes of Services ................................................................. 5

§3.01 Proposed Scope of Services for Solar PV System ............................................ 5

SECTION IV. Qualifications of the Project Team ........................................................ 8

§4.01 Key project team members ............................................................................... 8

SECTION V. Financial Proposal ..................................................................................... 9

§5.01 Project Cost....................................................................................................... 9

SECTION VI. Conclusion ........................................................................................... 11

 The page is
intentionally blank
 NAPERVILLE, • IL • 60563, • USA
(630) ENG-BITZ (PHONE)

Solar Photovoltaic System Proposal

SECTION I. Executive Summary

§1.01 The Project

Mr. Luis Escobar has issued an invitation to WCP Solar to provide pricing for a
renewable energy plant at their facility located at 430 Beverly Dr, Wilmette, IL
60091.

WCP Solar hereby submits this application for consideration as a bid for the provision
of engineering services for the installation of the proposed renewable energy
system.

The detail proposal estimates are presented in SECTION V. However, it should be

noted that these estimates are engineered estimates based on the scope of work
outlined in §3.01. It should also be noted that this proposal is a lump sum proposal
for such services as defined.

§1.02 Profile of Proposing Firm

WCP Solar Services, LLC (WCP Solar) is a firm established for the purpose of the
development of solar photovoltaic systems. WCP Solar is a licensed, bonded,
and insured full-service engineering, financially stable firm with headquarters
located in Naperville Illinois, USA.

At WCP Solar, we take care of every aspect of your solar investment including;
project consultation, complete site analysis, supply of solar materials and
equipment, electrical and structural engineering, permitting, financing,
installation, and maintenance.

Our management team has over 100 years of experience in the energy and
construction industries. Our highly qualified staff undergoes continuous training
on the latest solar technology. Our genuine passion for solar and decades of
real world experience make WCP Solar, the Solar Energy Experts.

Our #1 goal is complete customer satisfaction. Our supply chain includes

dealership agreements with manufactures and suppliers of all the material
needed to complete the installation of a solar system. We deliver the very best
in customer service and can manage projects of any size, from a small
residential system to large multi-acre solar farms. We use high quality
components throughout our photovoltaic (PV) systems to ensure dependable,
clean energy production for 30, 40, or even 50 years.

We service all market sectors; residential, commercial, non-for-profit, municipal,

agricultural, schools, and industrial. Our engineering staff works closely with the
client to provide custom solutions for their unique application. All systems
installed meet or exceed local and national construction and electrical
standards.
SECTION II. The Proposal
§2.01 Solar Photovoltaic (PV) System
The objective of this proposal is to provide an offer for the provision of
engineering services to 430 Beverly Dr, Wilmette, IL 60091 for the installation
of a 9.45-kWp solar photovoltaic system.

The proposed layouts for the solar plants are presented in Figure 1.

Figure 1 - Proposed System Layout

§2.02 System Production

The proposed 9.45-kWp solar plant is estimated to produce approximately
11,464 kW-h of energy annually as indicated in the Figure below.
 ,
Figure 2-Solar Contribution
SECTION III. Proposed Scopes of Services
§3.01 Proposed Scope of Services for Solar PV System
Based on the available roofing for the installation of a useful solar plant, it is
recommended that a 9.45-kWp Solar Photovoltaic System is installed on the
facility.

Accordingly, the proposal is being submitted for the provision of engineering

services that includes, engineering design, material supply, and installation of a
9.45-kWp solar plant in accordance with the local and national codes.

Consequently, the following tasks will be undertaken as a part of the proposed

scope of work:

1. Develop project schedule

a. A detailed project schedule shall be developed using a software

program.

b. This schedule shall be used to manage the permitting,

construction, and commissioning of the solar system.

2. Supply of system material

a. WCP Solar will supply the following components and apparatus:

i.PV modules,
ii.Racking structure and components
iii.PV Utility AC Disconnect Meter
iv. Utility Meter
v. Optimizers
vi. Inverters
vii. Revenue Grade Meter
viii. Data Acquisition System
ix.Breakers, load breaker, fuses, and PV and other types of
connectors.
x. Conduits, uni-strut, cable management hardware, PC
cables, and cable needed to make installation
xi. Transformer (if needed)
xii. Switchgears and disconnect switches
xiii. PV AC Switchboard(s)
xiv. Grounding system
xv. Required placards and labels
 xvi. Dumpsters, field office, etc.

Note: WCP Solar reserves the right to modify the presentation based on the final
system drawings.

3. Construct the solar plant

a. WCP Solar will develop a set of engineering drawings for the

proposed solar plant and submit for permit in accordance with
the requirements of the City of Wilmette.

b. WCP Solar will provide a construction team and install the

racking system, solar panels, and related apparatus for the
designed solar plant.

i. WCP Solar shall supply and install the required number of

string inverters to meet the system design requirements.

c. WCP Solar will provide electrical installers to perform the

electrical installation in accordance to the state ratio and design
guidelines.

4. Manage construction of solar plant

a. A management team will be supplied to oversee the installation

of the solar plant and conformance with the approved design
guidelines, safety, and quality procedures.

b. Management team will develop daily construction reports and

oversee all changes or modification in the construction program.

5. System Testing

a. WCP Solar will conduct testing of the system to provide base line
state of the installed solar plant. These tests will include I-V Curve
development and megger testing.

b. Testing will be completed immediately prior to commissioning of

the solar plant and several times during the construction phases
as deemed necessary by the Project Manager.

6. Develop a set of as-built stamped drawings,

a. Upon the successful commissioning of the solar plant, a detail set

of engineering drawings will be developed that will be used to
 document the manner of installation of the solar plant, cable
runs, and the location of the apparatus as was installed at the
plant. Changes from the original design set will also be noted
and explained.

7. Exclusions

a. This proposal assumes that the following items will not be

included and or will be supplied by others.

i. Applicable Taxes and Fees

ii. Conduct quality and safety audits except as required in
scope.
iii. Make modification of the client’s electrical service outside
of the general scope of work.
SECTION IV. Qualifications of the Project Team
§4.01 Key project team members
Table 1 – Key Personnel Involved in Project

Position Team Member

Principal Dr. Everton Walters
Senior Project Manager Asad Bajwa, P.E.
Electrician Pedro Paramo
Jr. Engineer Ken Vojtik

The people that will be involved in the provision of the engineering services are
as presented in Table 1 above. Kindly refer to the resumes attached for the
qualifications and experiences of the key team members.
SECTION V. Financial Proposal
The proposal is submitted to provide the turnkey solution for the solar system
as required. It is our intension to work closely with the Client in the future and
the proposal is developed and submitted within this framework. The proposal
is a lump sum price that will cover all the services as defined in the Scope of
Services as presented in paragraph §3.01.

§5.01 Project Cost

The proposed pricing is preliminary and based on the use of standard wage
guidelines. The pricing provided are preliminary based on the limited scope
of work and may change depending on the changes in the final proposal.
The pricing is presented in Table 2

Table 2- Estimated Cost of Services for Installation of 9.45-kWp Solar System

Type Line Items Total Cost

Purchased Services Design and Engineering $3,027.47
Installation $5,992.56
Material and Equipment PV Modules $5,481.00
Inverters $3,307.50
Mounting Equipment $1,486.01
Balance of System $1,747.31
Project management &
$6,548.11
Logistics
Total Cost for Solar Only $27,589.95

For the services provided as listed in paragraph §3.01, pricing is listed in Tables 2,
WCP Solar provides the following additional provisions:

1. WCP Solar provides 1 Year construction workmanship warranty for all

aspects of the installation.

2. WCP Solar provides insurance for all workers on the site during the
construction period (Workers Compensation, Auto, and General
Liability insurance).

3. WCP Solar will provide complementary maintenance of the system for

a period for not less than 5 years after commissioning.

4. WCP Solar will serve as the point of contact for all matters relating to
the solar installation for the life of the project.
 5. WCP Solar will provide any required training to the engineering staff of
the facility in relation to the safe operation of the solar plant.

Accordingly, it is estimated that the total cost for the installation of the
renewable energy system as specified will be $27,589
SECTION VI. Conclusion
WCP Solar proposes to make available its services to develop and provide
engineering services to aid in the development of a renewable energy system.

These systems will be integrated in the existing power plant system of the
property located at 430 Beverly Dr, Wilmette, IL 60091.

This renewable energy system will be installed on the site as designed and will
be installed in compliance with all local, state, and national codes.

The Company is pleased to present this proposal and hope that we have
addressed all issues. However, we will be available at your convenience to
discuss this matter further. Please contact us at (630) ENG-BITZ or at
[email protected].
 CASH FLOW PROJECTION
PROJECT SUMMARY
$50
Investment Tax Credit Rate 30.00%

Thousands
Electricity Rate $0.13103 /kW-h $40
System Size (Watt) 9,450 Wp
$30
Electric Inflation Rate 2.6%
Annual PV Degradation Rate 0.50% $20
SREC Rates $82.284 /MW-h
$10
Cost Per Watt $2.920 /Wp
PV System Cost $27,589.95 $0
Total Project Cost $27,589.95 0 4 8 12 16 20 24
-$10

SYSTEM Cash NET CASH FLOW

Electric (kW-h)
Year Annual Energy Savings REC Income ** Federal Tax Credit Cash Payments
Production Annual Cash Cumulative
0 11,464kW-h $1,502 $14,018 $8,277 -$27,590 -$3,793 -$3,793
1 11,407kW-h $1,532 $0 $0 $0 $1,532 -$2,261
2 11,350kW-h $1,562 $0 $0 $0 $1,562 -$698
3 11,293kW-h $1,593 $0 $0 $0 $1,593 $895
4 11,236kW-h $1,625 $0 $0 $0 $1,625 $2,520
5 11,180kW-h $1,657 $0 $0 $0 $1,657 $4,178
6 11,124kW-h $1,690 $0 $0 $0 $1,690 $5,868
7 11,069kW-h $1,724 $0 $0 $0 $1,724 $7,592
8 11,013kW-h $1,758 $0 $0 $0 $1,758 $9,350
9 10,958kW-h $1,793 $0 $0 $0 $1,793 $11,144
10 10,904kW-h $1,829 $0 $0 $0 $1,829 $12,972
11 10,849kW-h $1,865 $0 $0 $0 $1,865 $14,838
12 10,795kW-h $1,902 $0 $0 $0 $1,902 $16,740
13 10,741kW-h $1,940 $0 $0 $0 $1,940 $18,680
14 10,687kW-h $1,979 $701 $0 $0 $2,680 $21,359
15 10,634kW-h $2,018 $0 $0 $0 $2,018 $23,377
16 10,580kW-h $2,058 $0 $0 $0 $2,058 $25,436
17 10,528kW-h $2,099 $0 $0 $0 $2,099 $27,534
18 10,475kW-h $2,141 $0 $0 $0 $2,141 $29,675
19 10,423kW-h $2,183 $0 $0 $0 $2,183 $31,858
20 10,370kW-h $2,227 $0 $0 $0 $2,227 $34,085
21 10,319kW-h $2,271 $0 $0 $0 $2,271 $36,356
22 10,267kW-h $2,316 $0 $0 $0 $2,316 $38,672
23 10,216kW-h $2,362 $0 $0 $0 $2,362 $41,034
24 10,165kW-h $2,409 $0 $0 $0 $2,409 $43,443
Totals: 270,045kW-h $48,037 $14,719 $8,277 -$27,590 $43,443

Disclaimer
The figures presented in this document are for discussion purposes only and are not the basis of a Contract with WCP Solar. Please contact your Accountant and Attorney for advise on all accounting and legal issues.
WCP Solar Services, LLC do not testify to the accuracy of any of the figures presented in this document.
All income may be subject to federal and state taxes. Tax Calculations are for discussion purposes only. Please consult with your Accountant or Tax Attorney for determining your tax liability.
This quote is valid for 30 days. Quote Expiration Date: Thursday, November 3, 2022
 1 2 3 4 5 6 7 8 9 10

A A

B SYSTEM SIZE
B
DC 9.45 KW
SYSTEM SIZE
AC 7.6 KW

PROJECT NO.

TOTAL NO.
MODULES 21

PROJECT NAME AND ADDRESS:

RESIDENTIAL
C SOLAR PROJECT
C

430 BEVERLY DR
WILMETTE, IL

D D

E E

----
-- --
----

----
-- --
----
----
-- --
F ----
F
-- ---- --

DESIGNED BY: KEN VOJTIK 9/26/22

DRAWN BY: KEN VOJTIK 9/26/22
REVIEWED BY: ASAD BAJWA 9/26/22

SCALE:

DRAWING TITLE:

SITE
PLAN
G G
DRAWING NUMBER:

GA-300

1 2 3 4 5 6 7 8 9 10
ZXM6-NH144 Series
Znshinesolar 9BB HALF-CELL
Monocrystalline PERC PV Module

430W丨435W丨440W丨445W丨450W丨455W

Excellent cells efficiency

9BB 9BB technology decreases the distance between bus bars
and finger grid line which is benefit to power increase.

Better Weak Illumination Response

More power output in weak light condition, such as haze,
cloudy, and morning

Anti PID
Limited power degradation caused by PID effect is guaran-
teed under strict testing condition for mass production

High wind and snow resistance Znshine Standard

Industry Standard
5400 Pa snow load 2400 Pa wind load 100.0%
Guaranteed Power

97.5%

90.0%

84.3%
80.0%

25 years power warranty 1 5 12 15 25

Years
After 25 years our solar panel keeps at least 80% of its
initial power output
12 years product warranty
25 years output warranty

Higher lifetime Power Yield 0.55% Annual Degradation

over 25 years
2.5% first year degradation,0.55% linear degradation

Founded in 1988, ZNShine solar is a world’s leading high-tech PV module manufacturer. With the state-of-the-art production lines, the company boasts module
capacity of 6GW. Bloomberg has listed ZNShine as a global Tier 1 PV module maker. Today Znshine has distributed its sales to more than 60 countries around the
globe.

www.znshinesolar.com
 Znshinesolar 9BB HALF-CELL
ZXM6-NH144 Series Monocrystalline PERC PV Module

ELECTRICAL CHARACTERISTICS 丨 STC* DIMENSIONS(MM)

Barcode 1

Nominal Power Watt Pmax(W)* 430 435 440 445 450 455

Power Output Tolerance Pmax(%) 0~+3 0~+3 0~+3 0~+3 0~+3 0~+3

Maximum Power Voltage Vmp(V) 40.60 40.80 41.00 41.20 41.40 41.60

Maximum Power Current Imp(A) 10.60 10.67 10.74 10.81 10.87 10.94

Open Circuit Voltage Voc(V) 49.50 49.70 49.90 50.10 50.30 50.50

Short Circuit Current Isc(A) 11.19 11.26 11.33 11.40 11.46 11.53

Module Efficiency (%) 19.78 20.01 20.24 20.47 20.70 20.93

*STC (Standard Test Condition): Irradiance 1000W/m², Module Temperature 25℃, AM 1.5
*Measuring tolerance: ±3%

Front View
ELECTRICAL CHARACTERISTICS 丨 NMOT*
Drainage holes

Maximum Power Pmax(Wp) 321.50 325.20 328.90 332.70 336.10 339.80

Barcode 2

Label

Maximum Power Voltage Vmpp(V) 37.90 38.10 38.20 38.40 38.60 38.80 Mounting holes

Maximum Power Current Impp(A) 8.49 8.54 8.60 8.66 8.70 8.76

Open Circuit Voltage Voc(V) 46.20 46.40 46.60 46.70 46.9 47.1
Junction box

Short Circuit Current Isc(A) 9.04 9.09 9.15 9.21 9.25 9.31
*NMOT(Nominal module operating temperature):Irradiance 800W/m²,Ambient Temperature 20℃,AM 1.5,Wind Speed 1m/s
996

Grounding
Grounding holes
identification

MECHANICAL DATA
Solar cells Mono PERC Back View

Cells orientation 144（6×24）

Module dimension 2094×1038×35 mm(With Frame)

Weight 24 kg

Glass 3.2mm, High Transmission, AR Coated Tempered Glass

Junction box IP 68，3 diodes

Cables 4 mm² ,350 mm I-V CURVES OF PV MODULE(445W)

Connectors MC4-compatible 14

Cells temp. = 25 ° C

12 Incident Irrad. = 1000 W/m²

TEMPERATURE RATINGS WORKING CONDITIONS

10
Incident Irrad. = 800 W/m²
Current [A]

8
Incident Irrad. = 600 W/m²

NMOT 44℃ ±2℃ Maximum system voltage 1500 V DC 6

Incident Irrad. = 400 W/m²

Temperature coefficient of Pmax -0.36%/℃ Operating temperature -40℃~+85℃ 4

Incident Irrad. = 200 W/m²

2

Temperature coefficient of Voc -0.29%/℃ Maximum series fuse 20 A

0
0 10 20 30 40 50

Temperature coefficient of Isc 0.05%/℃ Maximum load(snow/wind) 5400 Pa / 2400 Pa Voltage [V]

*Do not connect Fuse in Combiner Box with two or more strings in parallel connection
*Remark:Electrical data in this catalog do not refer to a single module and they are not part of the offer.They only serve for comparison among different module types.
P-V CURVES OF PV MODULE(445W)
500

Cells temp. = 25 °C

PACKAGING CONFIGURATION
Incident Irrad. = 1000 W/m²
Incident Irrad. = 800 W/m²
400 Incident Irrad. = 600 W/m²
Incident Irrad. = 400 W/m²
Incident Irrad. = 200 W/m²
Piece/Box 30 300
Power [W]

Piece/Container(40’HQ) 660
200

Piece/Container(with additional small package) /

100

0
0 10 20 30 40 50 60

Voltage [V]

Add : 1#, Zhixi Industrial Zone，JintanJiangsu 213251，P.R. China Tel：+86 519 6822 0233 E-mail：[email protected]

Note: please read safety and installation instructions before using this product丨Subject to change without prior notice © ZNSHINE SOLAR 2021丨Version: ZXM6-NH144 2101.E
Data Sheet
Enphase Microinverters
Region: Internaltional

Enphase The high-powered smart grid-ready

Enphase IQ 7 Micro™ and Enphase IQ 7+ Micro™
IQ 7 and IQ 7+ achieve the highest system efficiency.

Microinverters Part of the Enphase IQ System, the IQ 7 and

IQ 7+ Micro integrate seamlessly with the Enphase
Envoy-S™, and the Enphase Enlighten™ monitoring
and analysis software.
The IQ 7 and IQ 7+ Micro extend the reliability
standards set forth by previous generations and
undergo over a million hours of power-on testing,
enabling Enphase to provide an industry-leading
warranty.

Easy to Install
• Lightweight and simple
• Faster installation with improved, lighter two-wire cabling

Productive and Reliable

• Optimized for high powered 60-cell and
72-cell* modules
• More than a million hours of testing
• Class II double-insulated enclosure

Smart Grid Ready

• Complies with advanced grid support, voltage and frequency
ride-through requirements
• Remotely updates to respond to changing
grid requirements
• Configurable for varying grid profiles

* The IQ 7+ Micro is required to support 72-cell modules

To learn more about Enphase offerings, visit enphase.com/au

Enphase IQ 7 and IQ 7+ Microinverters

INPUT DATA (DC) IQ7-60-2-INT IQ7PLUS-72-2-INT

Commonly used module pairings¹ 195 W - 340 W + 235 W - 420 W +
Module compatibility 60-cell PV modules only 60-cell and 72-cell PV modules
Maximum input DC voltage 48 V 60 V
Peak power tracking voltage 27 V - 37 V 27 V - 45 V
Operating range 16 V - 48 V 16 V - 60 V
Min/Max start voltage 22 V / 48 V 22 V / 60 V
Max DC short circuit current (module Isc) 15 A 15 A
Overvoltage class DC port II II
DC port backfeed under single fault 0A 0A
PV array configuration AC side protection requires max 20A per branch circuit
OUTPUT DATA (AC) IQ 7 Microinverter IQ 7+ Microinverter
Peak output power 250 VA 295 VA
Maximum continuous output power 240 VA 290 VA
Nominal (L-N) voltage/range² 230 V / 184-276 V 230 V / 184-276 V
Maximum continuous output current 1.04 A 1.26 A
Nominal frequency 50 Hz 50 Hz
Extended frequency range 45 - 55 Hz 45 - 55 Hz
Power factor at rated power 1.0 1.0
Maximum units per 20 A (L-N) branch circuit 16 (230 VAC) 13 (230 VAC)
Overvoltage class AC port III III
AC port backfeed under single fault 0A 0A
Power factor (adjustable) 0.7 leading ... 0.7 lagging 0.7 leading ... 0.7 lagging
EFFICIENCY @230 V @230 V
EN 50530 (EU) weighted efficiency 96.5 % 96.5 %
MECHANICAL DATA
Ambient temperature range -40ºC to +65ºC
Relative humidity range 4% to 100% (condensing)
Connector type MC4 (or Amphenol H4 UTX with additional Q-DCC-5 adapter)
Dimensions (WxHxD) 212 mm x 175 mm x 30.2 mm (without bracket)
Weight 0.92 kg
Cooling Natural convection - No fans
Approved for wet locations Yes
Pollution degree PD3
Enclosure Class II double-insulated
Environmental category / UV exposure rating Outdoor - IP67
FEATURES
Communication Power Line Communication (PLC)
Monitoring Enlighten Manager and MyEnlighten monitoring options
Compatible with Enphase IQ Envoy
Compliance (pending) AS 4777.2, RCM, IEC/EN 61000-6-3,
IEC/EN 62019-1, IEC/EN 62109-2

1. No enforced DC/AC ratio. See the compatibility calculator at enphase.com/en-us/support/module-compatibility.

2. Nominal voltage range can be extended beyond nominal if required by the utility.

To learn more about Enphase offerings, visit enphase.com/au

© 2017 Enphase Energy. All rights reserved. All trademarks or brands used are the property of Enphase Energy, Inc.
2017-12-05
This Contracting Agreement is made between WCP Solar Services, required drawings, specifications, and other such materials as
LLC, 1057 Shore Rd., Naperville, Illinois, 60563 (hereinafter referred to needed to satisfy the permit requirements.
as "Contractor”) and Owner and together referred to as “the Parties”. 12. No construction or site preparation work will be initiated until all
Contractor and Owner hereby agree as follows: necessary permits are obtained from the relevant authorities for
IN CONSIDERATION OF the mutual benefits and obligations set forth the subject Work Site.
in this Agreement, the receipt and sufficiency of which consideration is 13. Owner shall pay for all permits over and above the amount
hereby acknowledged, the parties to this Agreement agree as follows: budgeted in the proposal.
SERVICES PROVIDED PERFORMANCE
1. The Owner hereby agrees to engage the Contractor to provide the 14. Contractor may, at its discretion, engage licensed subcontractors
Owner with services (the "Services") consisting of designing, to perform work pursuant to this Agreement.
building, and installing a solar photovoltaic system as defined in
the Scope of Work. The Contractor hereby agrees to provide to the TERM OF AGREEMENT
Owner the services set forth in the Scope of Work.
15. The term of this Agreement will begin on the date of the execution
2. The Project shall be constructed on the property controlled by the of this Agreement by all parties and will remain in full force and
Owner and more particularly described as hereafter "the Work effect until the completion of the Services, subject to early
Site". termination as provided in this agreement.
3. Owner confirms that the Work Site is the Owner’s property or has
CONTRACT PRICE
control over the property. Owner shall defend, indemnify and hold
the Contractor, its officers, officials, and employees harmless from 16. For the services rendered by the Contractor as required by this
any and all claims, complaints, injuries, damages, losses, or suits Agreement, the Owner will pay to the Contractor compensation
including attorney fees, against Contractor arising out of claims amounting as presented in the Proposal.
made by parties other than Owner claiming an ownership interest
17. This Contract Price will be payable on the following basis;
in the Work Site.
a. Ten percent on approval and execution of agreement.
SCOPE OF WORK b. Thirty percent upon Approval of permit for the installation of
4. The Contractor shall design and install a grid-tied solar the solar plant. (To be used in securing the material for the
photovoltaic system having a combined name plate capacity as project. Additional payments made in the Managed Payments
presented in the Proposal that will provide renewable energy to the as needed).
Work Site. c. Subsequent Fifty percent payments (Managed Payments)
5. The system shall include solar photovoltaic collectors, mounting to be made weekly based on the percentage completion of
supports, electrical apparatus, and inverters. project.
6. The Contractor shall develop As-Builts and an operation and d. Ten percent upon completion of project and the delivery of
maintenance manual upon completion of the installation of the completion certificate to the Owner. Completion certificate
solar photovoltaic system. shall include approval from the AHJ of the installation and all
As-Builts.
WORK SITE
18. In addition to the lump sum project cost, the Owner is responsible
7. Owner hereby authorizes the Contractor to commence and for costs of all use tax on materials and other items purchased for
complete work on the Work Site as may be required in order to the Project, and increases in the Project Cost set forth in change
effectively complete the project. orders.
8. Owner understands that construction on the Work Site shall WORK CHANGES/ADDITIONAL COMPENSATION
include the installation of a solar photovoltaic system on the site
as described in the Contract Drawing. 19. Owner and Contractor reserve the right to order work changes in
the nature of additions, deletions, or modifications, without
PROJECT SCHEDULE invalidating the contract, and agree to make corresponding
adjustments in the contract price. All changes must be authorized
9. The Contractor shall develop and maintain an active project
by a written change order signed by the Owner and Contractor
schedule in an electronic format and shall host progress meetings
setting forth the changes to this Agreement and the price
with the Owner or their representative to discuss the work flow and
associated with said change. Work may be changed, and the
schedule.
contract price may be modified only as set out in the written
SURVEY AND TITLE change order. Any adjustment in the contract sum resulting in a
credit or a charge to the owner will be determined by mutual
10. The Contractor shall perform all necessary surveys of the Work agreement of the parties before starting the work involved in the
Site as needed to perform the design and installation. Payments change.
for all surveys shall be the sole responsibility of the Owner and are
an expense above and beyond the Contract Price. INSURANCE

PERMITS 20. Insurance required on this project shall be in accordance with the
following minimums. During the performance of the Services
11. The Owner with the aid of the Contractor shall apply for and obtain under this Agreement and for a period of six months after
such permits and regulatory approvals as may be required by the completion of the Project, Contractor shall maintain the following
local authority having jurisdiction (AHJ), municipal/county insurance with carriers having a Best's rating of at least A- and
government. Contractor shall develop and submit to the local authorized to do business in the state of Illinois.
authority having jurisdiction, municipal/county government the

Page | 1
 a. General Liability – a coverage with a limit of not less than OPERATION AND MAINTENANCE
$1,000,000 per occurrence/ $2,000,000 aggregate,
including a per-project endorsement. 30. The Contractor shall provide Operation and Maintenance (O&M)
services for one calendar (1) year following the commissioning,
b. Automobile Liability Insurance – to include coverage for operation, and acceptance of the project by the Owner.
all hired, owned, and non-owned vehicles, with a not less
than $1,000,000 per occurrence/ $1,000,000 aggregate. ENTIRE AGREEMENT
c. Workers' Compensation Insurance – statutory amount in 31. This agreement consists of the following documents:
accordance with the laws of the state in which the Services
are being performed, and Employers Liability Insurance with a. This Agreement in its entirety
limits according to such statutory requirements but shall be b. The following, which may be delivered, prepared, or issued after
no less than $1,000,000 for each accident or disease. the effective date of this Agreement and are not attached
hereto:
CAPACITY/INDEPENDENT CONTRACTOR
1. All Work Change Directives and Change Orders amending,
21. It is expressly agreed that the Contractor is acting as an modifying, or supplementing the Contract Documents.
independent contractor and not as an employee in providing the 2. Contract Specifications as developed in the execution of this
Services under this Agreement. The Contractor and the Owner Agreement. All apparatus cited in specification sheets are
acknowledge that this Agreement does not create a partnership or subject to change but shall be similar or equal in all respects
joint venture between them and is exclusively a contract for to the cited material in this document.
service.
3. Proposal Spreadsheets as presented and attached to this
COSTS AND LEGAL EXPENSES Agreement.

22. In the event that Contractor must bring legal action to enforce any i. The figures presented in the Proposal are estimates and are
term of this Agreement against Owner, Contractor shall be entitled presented for discussion purposes only.
to recover, in addition to any other damages or award, all ii. All income presented in the Proposal may be subjected to
reasonable legal expenses and fees associated with the action. state and/or Federal Income Tax and should be verified with
23. In the event that Owner must bring legal action, Contractor’s total the Owners Accountant.
liability for any breach of this Agreement, for any failure to perform iii. Contractor does not guarantee the accuracy of the figures.
any term of this Agreement, for any claims relating to or arising out iv. Prices presented in the Proposal are lump-sum and will not
of its performance of this Agreement, and for its own ordinary or change, except as provided by paragraph 19.
gross negligence (but not its reckless or willful misconduct) in any
4. Contract Drawings as developed in the execution of this
aspect of its relationship with Owner shall not exceed the monies
Agreement.
paid to and received by Contractor under this Agreement.
GOVERNING LAW
TERMINATION OF CONTRACT
32. It is the intention of the parties to this Agreement that this
24. The Client may terminate this agreement within three (3) calendar
Agreement and the performance under this Agreement and all
days from the date of execution for any reason, real or imagined.
suits and special proceedings under this Agreement, be construed
However, this rescission option is vacated after the 3 days have
in accordance with and governed, to the exclusion of the law of
expired and the contract takes full effect at that time.
any other forum, by the Illinois state laws. The parties agree that
25. The Contractor may terminate this agreement at any time based on any legal disputes shall be filed in the Circuit Court of Cook
any material breach of the terms of the contract including failure of County, Illinois or the Circuit Court of DuPage County, Illinois.
the Owner to make a payment on time as specified in this
Agreement. MISCELLANEOUS

ACTS BEYOND CONTROL 33. The Owner and Contractor each binds itself, its partners,
successors, and assigns, in respect to all covenants, agreements,
26. Contractor shall not be liable for any delay due to circumstances and obligations contained within the Contract Documents.
beyond its control including but not limited to strikes, permit
approvals, casualty, acts of God, illness, injury, weather, soil 34. No assignment by a party hereto of any rights under or interests in
conditions, or general unavailability of materials. the Contract Documents will be binding on another party hereto
without the written consent of the party sought to be bound.
WARRANTY AND CONSULTATION SERVICES 35. Any provision or part of the Contract Documents held to be void or
27. The Contractor shall provide a general warranty that shall be unenforceable under any Law or Regulation shall be deemed
limited to defects in workmanship that may arise and become stricken, and all remaining provisions shall continue to be valid and
known within One (1) year from the Project Completion Date. binding upon Owner and Contractor, who agree that the Contract
Documents shall be reformed to replace such stricken provision or
28. The Warranty for Materials shall be that provided by the material part thereof with a valid and enforceable provision that comes as
provider. Contractor shall have no obligation to Owner regarding close as possible to expressing the intention of the stricken
the material warranties. provision.
29. The Contractor shall provide consultation services for a period of 36. This Agreement may be executed in any number of counterparts,
Fifteen (15) years following the Project Completion Date. each of which is deemed an original but all of which constitute the
Consultation services shall include the following: same instrument. This Agreement may be executed by the
a. Answering questions concerning the maintenance and exchange of faxed executed copies, certified electronic signatures
functionality of the system. or copies delivered by electronic mail in Adobe Portable
b. Make recommendations of corrective actions to be taken by Document Format or similar format, and any signature transmitted
selected contractor. by such means for the purpose of executing this Agreement is
c. Site visits shall be at market time and material rates and travel deemed an original signature for purposes of this Agreement.
shall be at standard mileage rates.

Page | 2
CUSTOMER SIGNATURE

By signing below:
I certify that, as the Customer Representative, I have the authority to bind the Customer to these Terms and
Conditions.
Customer agrees to the installation of the proposed solar photovoltaic system as described in the proposal. I
have been informed of the installation costs of the specified solar plant.
I have read, understand, and agree to comply with the terms and conditions set forth in this Agreement.

SIGNED, SEALED, AND DELIVERED

OWNER CONTRACTOR

WCP Solar Services, LLC

Dr. Everton Walters
President/CEO

Date Date

Page | 3
(630) 729-2099 (Tel)
800-WCP-0717
(630) 995-3457 (Fax)

www.wcpsolar.com